OHE work for provision of Two New full length line approx. 750 mtr. One common loop in UP direction and One in DN direction at Chhatna station in Adra division

• EXECUTION OF AGREEMENT:The Tenderer whose tender is accepted shall be required to appear in person at the office of General Manager/General Manager (Construction), Chief Administrative Officer (Construction), Divisional Railway Manager or concerned Engineer, as the case may be, or if tenderer is a firm or corporation, a duly authorized representative shall appear (there would be no need for appear in person if agreement is signed digitally) and execute the contract agreement within seven days of notice from Railways that the Contract Agreement is ready. Failure to do so shall constitute a breach of the agreement affected by the acceptance of the tender. The Contract Agreement shall be entered into by Railway only after submission of valid Performance Guarantee by the Contractor. In such cases the Railway may determine that such tenderer has abandoned the contract and there upon his tender and acceptance thereof shall be treated as cancelled and the Railway shall be entitled to forfeit the full amount of the Bid Security and other dues payable to the Contractor under this contract. The failed Contractor shall be debarred from participating in the re-tender for that work.

  Show more

• RAILWAY PASSES No free Railway passes will be issued for the contractor

• SPECIFIED RAILWAY STORES Materials which are to be supplied by the Railways for Execution of the work will be handed over to the contractor by the consignee from his store against Indemnity Bond.

• REFUND /FORFIETURE OF Bid security As mentioned in GCC-April-2022.

• COMMUNICATION TO BE IN WRITING All notices communications, reference and complaints made by the purchaser of his Engineer or the Engineers representative or the contractor concerning the works shall be in writing and no notice communications reference or complaint not in writing shall be recognized. The list of addresses to which correspondence and documents relating to the contract should be sent are indicated in the tender papers

• SERVICE OF NOTICES ON CONTRACTORS The contractor shall furnish to the Engineer the name, designation and address of his authorized agent and all complaints , notices, communications and references shall be deemed to have been so duly given to the contractor if delivered to the contractor left at or posted to the address so given and shall be deemed to have been so given in the case of posting on the day on which would have reached such address in the ordinary course of post or on the day on which they were so delivered or left in the case of contract by partners, any change in the constitute of the firm shall be forthwith notified by the contractor to the Engineer. Important documents may be sent by REGISTERED POST.

• SUBLETTING OF CONTRACT As mentioned in GCC-April-2022.

• RETURN OF UN-UTILISED MATERIALS OF THE PURCHASER Such materials as have been issued to the contractor but left behind with him UN-UTILISED, shall be determined after reconciliation with the actual quantum of issued vis-a-vis utilized for execution of the work and returned by the contractor to the purchasers depot at no extra cost in the same shape and condition of the materials as were issued to the contractor(s). If the contractor fails to return such materials, the cost of such will be recovered at a rate at twice the book rate or twice the market rate enhanced by 20 . 38 % whichever is higher. Every effort will be made by the purchaser to supply the materials as listed in part-II at the appropriate time. However suitable extension of time will be granted to the contractor in case of delay for supply of said materials by the purchaser any reason whatsoever and no claim of compensation from the contractor for such delay by the purchaser will be entertained. NOTE:The contractor shall hand over all empty drums, wooden carats and other packing materials used for the issue of purchasers materials to the purchasers depot

  Show more

• CARRIAGE OF MATERIALS No forwarding orders shall be issued by the purchaser for the transportation of Contractors materials, tools and plant by rail or by road to the work site which may be required for use in the works and the contractor shall pay full freight charges at public tariff /rates there for. No Road permit for contractors supply material will be issued by Railways

• PROVISION OF EFFICIENT AND COMPETENT SUPERVISOR The Contractor shall place and keep on the works at all times efficient and competent staff to give the necessary directions to his workmen and to see that they execute their work in sound & proper manner and shall employ only such supervisors, workmen & labourers in or about the execution of any of these works as are careful and skilled in the various trades.The Contractor shall at once remove from the works any agents, permitted sub-contractor, supervisor, workman or labourer who shall be objected to by the Engineer and if and whenever required by the Engineer, he shall submit a correct return showing the names of all staff and workmen employed by him.In the event of the Engineer being of the opinion that the Contractor is not employing on the works a sufficient number of staff and workmen as is necessary for proper completion of the works within the time prescribed, the Contractor shall forthwith on receiving intimation to this effect deploy the additional number of staff and labour as specified by the Engineer within seven days of being so required and failure on the part of the Contractor to comply with such instructions will entitle the Railway to rescind the contract under Clause 62 of these conditions.

  Show more

• Deployment of Qualified Engineers at Work Sites by the Contractor: As mentioned in GCC-April-2022.

• ACCIDENTS AND DAMAGES TO INSTALLATIONS ETC The contractor shall be responsible for all repairs and rectification of damage to installations erected or under erection due to accident or any other cause during the course of the contractors work at site inclusive of the guarantee period at no extra cost to the purchaser. All costs, damages or expense which the purchaser may incur, for which under the terms of contract, the contractor is liable may be either deducted by the purchaser at his discretion from any money due or to become due to refundable by the purchaser to the contractor under the contract , or may be recovered by action of law or otherwise from the contractor . The purchaser reserve the right and shall be entitled to retain payments due to the contractor under this contract and to set off the same against all claims whether arising out of this contractor out of any other transaction whatever with the contractor.

  Show more

• PROVISION OF PAYMENT OF WAGES ACT The contractor shall comply with the provision of payment of wages Act 1936 as amended up to date and the rules made thereunder in respect of all employees employed by him in the works, if in compliance with the terms of the contract , the contractor directly or through the petty contractors or subcontractors shall supply any labour to be used wholly or partly under the direct orders and control of the engineer whether in connection with the work to be executed here under or otherwise for the purpose of the engineer such labour shall never the less be deemed to be , comprise of person employed by the contractor and any money which may ordered to be paid by the engineer on behalf of the contractor and engineer may on failure by the contractor to repay such moneys due to the contractor in terms of the contractor. The purchaser shall be entitled to deduct from any moneys due to the contractor (whether under the contract or any other of compensation of aforesaid or for costs of expense in connection with any claim there) and the decision of the engineer upon any question arising out of the effect or force of this clause shall be final and binding upon the contractor. All the condition as mentioned in GCC-APRIL-2022 are applicable for PROVISION OF PAYMENT OF WAGES ACT.

  Show more

• WAGES TO LABOUR The Contractor shall be responsible to ensure compliance with the provision of the Minimum Wages Act, 1948 (hereinafter referred to as the "said Act") and the Rules made thereunder in respect of any employees directly or through petty Contractors or sub-contractors employed by him for the purpose of carrying out this contract. If, in compliance with the terms of the contract, the Contractor supplied any labour to be used wholly or partly under the direct orders and control of the Railways whether in connection with any work being executed by the Contractor or otherwise for the purpose of the Railway such labour shall, for the purpose of this Clause, still be deemed to be persons employed by the Contractor.If any moneys shall, as a result of any claim or application made under the said Act be directed to be paid by the Railway, such money shall be deemed to be moneys payable to the Railway by the Contractor and on failure by the Contractor to repay the Railway any moneys paid by it as aforesaid within seven days after the same shall have been demanded, the Railways shall be entitled to recover the same from Contractor's bills/Security Deposit or any other dues of Contractor with the Government of India.The Contractor shall be responsible to ensure compliance with the provisions of the Apprentices Act, 1961 and the Rules and Orders issued thereunder from time to time in respect of apprentices directly or through petty Contractors or sub-contractors employed by him for the purpose of carrying out the Contract. If the Contractor directly or through petty Contractors or sub-contractors fails to do so, his failure will be a breach of the contract and the Railway may, in its discretion, rescind the contract. The Contractor shall also be liable for any pecuniary liability arising on account of any violation of the provisions of the Act.

  Show more

• 1. Powers of Modification to Contract: As per GCC-APRIL-2022.

• COMPLIANCE TO ENGINEERS INSTRUCTIONS The Engineer shall direct the order in which the several parts of the works shall be executed and contractor shall execute without delay all orders given by the engineer from time to time but the contractor shall not be relieved thereby from responsibility for the due performance of the works in all respects. Alternations to be authorized: No alternations in or additions to or commission or abandonment of any part of the works shall be deemed authorized except under instructions from the engineer and the contractor shall be responsible to obtain such instruction in each and every case.

• EXTRA WORK Should works over and above those included in the contract required to be executed at the site the contractor shall have no right to entrust with the execution of such works which may be carried out by another contractor or contractors or by other means at the options of the purchaser. Separate contract in connection with works: The purchaser shall have the right to let other contractors in connection with the works the contractor shall afford other contractor reasonable opportunity for the storage of their materials and the execution of their works and shall properly connect and co-ordinate his works there. If any part of the contractor work depends for proper execution or result upon the work of another contractor, the contractor shall inspect and accordingly report to the engineer any defects in such work that render it unsuitably for such proper execution and result . The contractors failure so to inspect and report shall constitute acceptance of the other contractors work except as to defects which may have developed in the other contractors work after the execution of his work.

  Show more

• ILLEGAL GRATIFICATION Any bribe, commission, gifts or advantages given, promised or offered by or on behalf of the contractor or his partner, agent or servant or any one of his or on their, behalf in relation to the obtaining or the execution of this or any other contract with purchaser shall in addition to any original liability which he may incur , subject to the contractor to the recession, of the contract and all other contracts with the purchaser and to the payment of any loss or damage resulting from such rescission and the purchaser or damage resulting from such rescission and the purchaser shall be entitled to deduct the amount so payable from any money due to the contract under the contract or any other contracts with the purchaser. The contractor shall not lend or borrow from or have or enter into any monetary dealings or transactions either directly or indirectly with any employee of the purchaser and if he shall do so the purchaser shall be entitled forthwith to rescind the contracts and all other contracts with the purchaser. Any question or dispute as to the commission of any offence or compensation payable to the purchaser under this clause shall be settled by the General Manager in such manner as he shall consider fit and sufficient and his decisi on shall be final and conclusive.

  Show more

• ADHERENCE TO SPECIFICATION AND DRAWINGS The whole of the works shall be executed in perfect conformity with specifications and drawings of the contract. If the contractor performs any work in manner contrary to the specifications or drawings or any of them and without such reference to the engineer, shall have to bear all the costs arising of ensuring and shall be responsible for the losses to the purchaser.

• WORKS BY OTHER AGENCIES Any other works undertaken at the same time by the purchaser direct or through some other agency at the same site where the contractor is carrying out his work, will not entitle the contractor to prefer any claim regarding any delays or hindrances he may have to face on this account . The contractor shall comply with any instruction which may be given to his by the purchaser in order to permit simultaneous execution of his own works and of those undertaken by other contractors or the purchaser without being entitled on this account to any extra charge.

  1. If the purchaser is unable to supply materials to the contractor as specified in the contract in time, the contractor shall not be entitled to any extra payment on account of such delay in supply, however such delays in supplies will be reasonable ground for extension of completion dates for the works.
  2. All materials will be subjected to inspection and test either by the purchaser or by an agency appointed for this purpose for individual items as below, at the manufacturers work before dispatch and no materials shall be dispatched from the manufacturers works until these are inspected and or approved . These materials may also again be inspected at the contractors depot/work site . The purchaser or his representative shall have the right to be present during all stages of manufacture and shall be afforded free of charge all reasonable facilities for inspection and testing so as to satisfy himself/themselves that the materials are in accordance with specifications, approved drawings and designs. Any reasonable delay in inspection will be a reasonable ground for extension of time for completion of works.
  Show more

• PROVISIONAL ACCEPTANCE Immediately after the completion of an installation the contractor will certify and advice the purchaser in writing that the installation is :

  1. Complete .
  2. Ready for satisfactory regular service and
  3. Ready to be handed over. He will also place at disposal of the purchaser the required staff for inspection, testing and putting it into operation. The test or test specified in any clauses will be conducted jointly by the purchaser and contractor as soon as possible after receipt of advise of completion of an installation by the purchaser from the contractor.After the purchaser is satisfied with the satisfactory working of the installation, he will issue a Provision Acceptance Certificate which would be signed by both the parties. Should the results of inspection and tests be not satisfactory an extension of time for one month will be granted to make good defects and deficiencies pointed out by the purchaser. A fresh inspection and tests will then be carried out after the contractor has attended to the defects and deficiencies . If these are not satisfactory , the purchaser may proceed at the contractors expense by all means deemed expedient to have the installation made approved drawings and designs.
  Show more

• PROVISIONAL ACCEPTANCE In such a case or in case of delay in completing the work under this contracts within the time limit the purchaser reserves the right if he deems it possible to use in a reasonable manner any part of the installation even if the work is not completely erected. The purchaser will give to the contractor for this purpose seven days previous notices. The contractor shall then take at his own expenses all necessary steps to complete the works in accordance with the provisions of the contract. In case it becomes impossible to proceed with the above mentioned taking over tests, for reasons other than for which the contractor is responsible, the provisional acceptance certificate shall be issued at or within a mutually agreed reasonable period not exceeding six months after completion of an installation. NOTE: The issue of provisional acceptance certificate will not be withheld for rectification of minor defects as distinct from rejected equipment, which may not be essential for energization and operation of the installation in such cases, only the value of materials and cost of rectification of the minor defects shall be withheld from payments on provisional acceptance until rectification is completed.

  Show more

• WARRANTY The contractor shall warranty satisfactory working of the installation erected by him , for a period of twelve months from the date of provisional acceptance of each installation(Para 38 i.e. provisional acceptance by the purchaser ). During this period the contractor shall make available an experienced Engineer and necessary equipment to attend to any defective installation and be responsible for satisfying himself that the purchasers staff follow the prescribed procedure for operation and maintenance of equipment . The contractors shall bear the cost of all modifications, additions or substitutions that may be considered necessary due to faulty materials , designs or workmanship for the satisfactory working of the equipment. The final decision shall rest with the Sr. Divisional Electrical Engineer (TRD), S. E. Railway , Adra. During the period of guarantee the contractor shall be liable for the replacement of any parts which may be found defective in the equipment whether such equipments be of his own manufacturer or those of his sub-contractors whether arising from faulty design, materials, workmanship or negligence in any manner on the part of the contractor provided always that such defective parts as are not repairable at site are promptly returned to the contractor if so required by him at site(contractors own expenses). The contractor shall bear the cost of repairs carried out on his behalf by the purchaser at site. In such a case the contractor shall be informed in advance of the works proposed to be carried out by purchaser.

  Show more

• Warranty If it becomes necessary for the contractor to replace or renew any defective portion of the equipment under the clause aforesaid then the provision of the said clause shall also apply to the portions of the equipments so replaced or renewed until the expiration of six months from the date of such replacement or until the end of the above mentioned period of twelve months, whichever is later, such extension shall not apply in case of defects of a minor nature, the decision of the Sr. Divisional Electrical Engineer (TRD), S. E. Railway , Adra being final in the matter, if any defects be not remedied within a reasonable time during the aforesaid period the purchaser may proceed to do the work at the contractors risk and expense, but without prejudice to any other rights and remedies which the purchaser may have against the contractor in respect of such defects or faults. The repaired or renewed parts shall be delivered and erected at site free of charges to the purchaser. Any materials supplied shall also be covered by the provisions of this clause. The liability of the contractor under the guarantee will be limited to re- supply of materials made under clause 38 such supply shall be effected at the contractors depot or in the event of closure of the depot at the stores depot of the engineer at site covered by the contract. In case of materials supplied by the purchaser under clause 38 no liability will rest on the contractor for failure on account of defects inherent in such materials .

  Show more

• FINAL ACCEPTANCE The final acceptance of the installation shall take effect from the date of expiration o f the period of guarantee as defined in warranty clause provided the installation previously accepted provisionally are still in good working order . If on the other hand the installation is not in good working order at the end of the guarantee period the purchaser may either extend the period of guarantee until, necessary works are carried out by the contractor or carry out those works or have them carried out successfully on behalf of the contractor and at his expenses . A certificate of final acceptance shall then be issued under the signature of both the parties The purchaser and the contractor

• SUPPLY OF SPARE PARTS The supply of spare parts, components, standby equipments shall be so regulated that all the necessary items that have been ordered shall be delivered at site only after the erection of the main equipments but before the testing and commissioning of system. If the spare parts standby equipments are to be supplied in advance, necessary written and specific permission shall be taken from the engineer

• ACCOMMODATION The contractor shall make his arrangements for the accommodation of his staff, materials, tools etc, electricity for the purpose of execution of the work against this contract may be arranged by railway from its sources , if available near the work site on payment of railways specified charges.

• LAWS OF INDIA This contract shall be governed by the laws for the time being in force in the Republic of India.

• DEFAULT AND DELAY The contractor shall execute the work with due diligence and expedition keeping to the approved time schedule duly executing the work in proportionate to the given time schedule as per TDC . Should he refuse or neglect to comply with any reasonable orders given to him in writing by the purchasers engineers in connection with the work or contrivance the provision of the contract or the progress of work lags persistently behind the time schedule due to his neglect , the purchaser shall be at liberty to be given seven days notice in writing to the contractor requiring him to make good the neglect or contravention, complained of or should the contract fail to comply with the requisition made in the notice within seven days from the receipt thereof, it shall be lawful for the purchaser to take the work wholly or in part out of the contractors hands without any further reference and get the work or any part thereof as the case may, completed by other agencies at the expense of the contractor , if applicable as per extant rule without prejudice to any other right or remedy of the purchaser .

  Show more

• LOSS SUSTAINED DUE TO DEFAULT AND DELAY

  1. In the event of any loss to the purchaser on account of execution and/or completion of the work or any part thereof by agencies other than the contractor, in terms of appropriate clauses, the contractor shall be liable to reimburse the loss to the purchaser without prejudice to the other rights and remedies of the purchaser, and the reimbursement in full or in part as the case may be, shall be met, at the option of the purchaser, from out of all or any of the following sources viz.
     1. Any amount due and payable to the contractor by the purchaser on any account whatsoever.
     2. The contractors security deposit in the hands of the purchaser as far as Available and
     3. Any other assets whatsoever of the contractor.
  2. In the event of reimbursement from out of sources
     1. and or
     2. above mentioned, the purchaser shall have the right of appropriation sue motto.
  Show more

• CORRECTNESS OF WORK AND MATERIALS

  1. All designs and drawings submitted by the contractor shall be based on a thorough study and shall be such that the contractor is satisfied about their suitability . Notwithstanding approval communicated by the purchaser, during the progress of the contract , for designs and drawings prototype samples of components , materials and equipments after inspection and adjustments to installations. The ultimate responsibility for correct design and execution of work shall rest with the contractor unless the purchaser insists on adoption of his own designs in spite of the contractor not being agreeable to its .
  2. If any dimension figured upon a drawing differs from that obtained by sealing the drawings the figures dimension should be normally taken as correct unless it is prima facie a mistake but all such cases shall be brought to the notice of the purchasers engineers and the discrepancy set right before execution .
  Show more

• CONTRACTORS RESPONSIBILITY FOR DISCREPANCY

  1. All designs and drawings submitted by the contractor shall be based on a Thorough study and shall be such that the contractor is satisfied about their suitability . Not withstanding approval communicated by the purchaser , during the progress of the contract , for designs and drawings, prototype samples of components , materials and equipments after inspection and adjustments to installations, the ultimate responsibility for correct design and execution of work shall rest with the contractor unless the purchaser insists on adoption of his own designs in spite of the contractor not being agreeable to its.
  2. The contractor shall be responsible for and shall bear and pay the costs for any alternation of works arising from any discrepancies , errors or omissions in the designs and drawings have been approved by the purchaser or not .

• ADDITIONS AND ALTERATIONS TO ERECTED EQUIPMENTS The purchaser may require additional installations or modifications to be carried Out on the works he deems necessary, either during the execution or after a part or whole of the installations coming within the purview of the contract has been put into commercial service. In case the prices for such additional works or modifications are not covered by the Schedule of prices and are such that either partly consider additional prices for such Works justified , such additional works o r modification shall be carried out, only after the additional prices proposed by the contractor are accepted by the purchaser In case additional installations or modifications are required to be carried out under this para, the purchaser shall grant a reasonable extension of time, should this be considered necessary.

• ISSUE OF TOOLS AND PLANTS TO THE CONTRACTOR:For the purpose of carrying out the work , Railway will not issue any tools and plants. However, if the executive officer in charge of the work is of the opinion that in the interest of faster progress of the work, any tools and plants items are to be provided to the contractor, the same may be provided to the contractor on fulfilling of an indemnity bond and the book value of the materials will kept deducted from running bills of the contractor till return of the tools and plants. The determination of book value of the T&P items is as per the Railways book or the cost of procurement of the item with normal escalation @ 10% per year added to it, whichever is higher.

• Conservancy cess charges shall be deducted from on account bills in accordance with Rly Board letter No. F(X)I- 95/1/1 dt.07.09.2021 with its latest amendment ,if any . At present proposed conservancy Cess Charges to be recovered PER MONTH from Railway Contractors:a.Engg. Works Contractors (Engg, Elect. Mech. Signal etc.)for Average no. of Labourer or Workman Employed per day as applicable.

• Imposition of LD for delay in the completion work. As per the clause laid under GCC- April-2022.

• UNIT PRICES (1.)The rate quoted by the tenderer and accepted by the purchaser shall hold good till the completion of the work and no additional individual claim will be admissible on account of fluctuation in market rates etc. or due changes in tax structures unless otherwise stated under appropriate clauses . (2.) The tenderer should quote rate with all taxes including GST with all incidental charges like freight, Transport, loading /unloading, handling of materials , lifting , descent, insurance Coverage or bankers charges, indemnity bond etc.

• EXPLANATORY NOTES Explanatory notes for various items of works included in the schedule-I and schedule-II are given under Technical compliance of the tender . Tenderer should carefully read technical compliance wherein each schedule items have been clearly explained .

• TERMS OF PAYMENT

  1. Subject to any deduction or recoveries which the purchaser may be entitled to make under the contract, the contractor shall unless otherwise agreed to be entitled to get the payments subject to conditions stipulated in the subsequent clauses.
  2. Payment will be arranged by Sr. Divisional Finance Manager, S.E.Railway, Adra for the bills submitted to Sr. Divisional Electrical Engineer (TRD)/Adra, through Depot-in-charge, subject to following :-
     1. Execution of indemnity bond on stamp duty in case of any materials taken by contractor from Railways.
     2. The bills for payment should accompany a copy of penalty imposed during the execution of the work for which payment is claimed and clearing certificate from the Depot-in-charges, indicating the successful job completed by tenderer.

• ON ACCOUNT PAYMENT On account payment to the extent of 85% will be made on the total unit price of such items included in the schedule of prices only for those items included in the schedule of prices and executed in terms of this contract for which Sr. Divisional Electrical Engineer (TRD), S. E. Railway, Adra considers appropriate and acceptable to make the on account payment. All invoices shall be accompanied by the :

  1. Contractors challan along with manufacturers/suppliers challan for supply of items only.
  2. Inspection certificate granted by the Inspecting authority as authorized by Sr. Divisional Electrical Engineer (TRD), S. E. Railway, Adra.
  3. Execution of indemnity bond on stamp duty in case of materials supplied by the Railways.
  4. Certificate of current statutory taxes and duties.
  5. Detailed entries made in the Measurement Book.

• FINAL PAYMENT Balance 15% payment will be made through the final bill only after satisfactory completion of the entire contractual work , satisfactory operation and handing over of the assets to the Railway duly tested and commissioned subject to compliance of the following application:

  1. On supply of catalogue and operation manual/instruction books wherever applicable.
  2. On supply of as Erected Drawing of the equipment/installation, if applicable.
  3. A No claim certificate in favour of Railway is issued by the contractor.

• PAYMENT FOR SPARES AND FOR ADDITIONAL SUPPLIES The contractor shall be eligible for receipt of full 85% payment for supply of spares and additional supplies ordered on him in accordance with prices included in the schedule after handing over of the spares to the Railway in good working condition. Balance 15% payment will be made through final bill.

• PAYMENT OF STATUTORY VARIATION IN TAXES AND DUTIES The unit prices quoted by the tenderer and accepted by the Railway Administration Shall be firm. Also the purchaser will not be responsible for payment of duties and taxes made by the tenderer under misappropriation of law.

• FINAL SETTLEMENT AND REFUND OF SECURITY DEPOSIT On expiry of the warranty period and issue of the certificate for final acceptance produced all the dues payable by the contractor to the Railway have been duly paid or otherwise made good by the contractor, the security deposit will be refunded to the contractor on production and surrender of the relative original receipts granted by the Railway in case it was paid in cash, The security deposit shall however , be liable to the forfeited in case of any breach by the contractor of any of the conditions of the contract or for non completion of the full contract without prejudice to other rights and remedies of the Railway whether specifically provided for herein or otherwise.

• POST PAYMENT AUDIT It is an agreed term of the contract that the Railway reserves to itself the right to carryout a post payment audit and or technical examination of the works and the final bills, including all supporting vouchers, abstracts etc. and to make a claim on the contractor for the refund of any excess amount paid to him if as a result of such examination any over payment to him is discovered to have been made in respect of any work done or alleged to have been done by him under the contract.

• MEASUREMENT Payment for the work shall be made in accordance with the specifications, approved designs and drawings and measured in relevant units . The measurement will be made generally in accordance with Tender schedule in conformity with the explanatory notes of the Tender schedule , specification and standard engineering practices.

• MEASUREMENT OF WORK :As per the condition mentioned in GCC-April-2022

• Right of RAILWAY to determine the CONTRACT as per GCC clause no.61 (1) : The Railway shall be entitled to determine and terminate the contract at any time should, in the Railway's opinion, the cessation of work becomes necessary owing to paucity of funds or from any other cause whatever, in which case the value of approved materials at site and of work done to date by the Contractor will be paid for in full at the rate specified in the contract. Notice in writing from the Railway of such determination and the reasons therefor shall be conclusive evidence thereof.

• 62.(1) Determination Of Contract Owing To Default Of Contractor : If the Contractor should : As per GCC-APRIL- 2022

• DETERMINATION OF CONTRACT As per GCC-April-2022.

• GCC clause- 62(2) Right Of Railway After Rescission Of Contract Owing To Default Of Contractor : As per GCC- April- 2022.

• GCC Clause no. 64.(1) Demand For Arbitration : As per GCC- April-2022.

• RATES:Tenderer should quote only the uniform percentage aboveor below or at par to each schedule i.e. single rate for eachschedule. Tender Value inclusive of all taxes as applicable (GST @ 18 %). Offers are to be submitted by thetenderers as per GST regime. CONDITIONAL OFFERS WILL BESUMMARILY REJECTED.

• TAX DEDUCTION:

  1. Income Tax @ 2% plus surcharges as applicable on the amount to be paid by the contractor in pursuance of the contract which will be deducted from the bills preferred by him in accordance with section 1204C of the Income Tax Act 1961 as introduced through finance Act of 1972 or as amended from time to time, as per extant rule will be recovered wherever it is applicable.
  2. Conservancy cess charges are also recoverable in accordance with Railway Board letter No. F(X)I-95/1/1 dt. 07.09.2021 or as per extant rule of Railway with the latest amendment, if any, if the site of work falls under the Railway settlement limit.
  3. Any other taxes/charges levied by the Govt. from time to time will be recovered wherever it is applicable

• Deployment of Qualified Engineers at Work Sites by the Contractor: 26A.1The Contractor shall also employ qualified Graduate Engineer(s) or equivalent, or qualified Diploma Engineer(s),as prescribed in the tender documents. 26A.2 In case the Contractor fails to employ the Engineer, as aforesaid in Para 26A.1, he shall be liable to pay liquidated damages at the rates, as prescribed in the tender documents. 26A.3 No. of qualified Engineers required to be deployed by the Contractor for various activities contained in the works contract shall be specified in the tender documents as 'Special Condition of Contract'.

  1. Cost of work Rs.200 Lakhs and above- One Graduate Engineer.
  2. Cost of work more than Rs.25 Lakhs but less than Rs.200 Lakhs- One Diploma Holder Engineer. Note:- Track related contractual works of values as specified in para-b, individuals having Diploma in Railway Engineerig awarded by IPWE- India shall also be considered as qualified Diploma Holder Engineers and contractors for track contract works can employ such individuals at their worksite on Indian Railway vide Rly. Bds letter No. 2012-CE-I- CT-O-20, Dt- 12.07.2013. In case the contractor fails to employ the Qualified Engineer, as aforesaid in para above, he or him in terms of provisions of clause 26A.2 to the General Conditions of Contract, shall be liable to pay an amount of Rs.40,000 and Rs.25,000 for each month or part thereof for the default period for the provisions as mentioned in para-a and b above respectively.
  Show more

• Bid Security:-The tenderer shall be required to submit the Bid Security with the tender for the due performance with the stipulation to keep the offer open till such date as specified in the tender, under the conditions of tender. The Bid Security shall be as mentioned in GCC-April-2022,

  1. The Bid Security shall be rounded off to the nearest 100. This Bid Security shall be applicable for all modes of tendering.
  2. Any firm recognized by Department of Industrial Policy and Promotion (DIPP) as 'Startups' shall be exempted from payment of Bid Security detailed above.
  3. Labour Cooperative Societies shall submit only 50% of above Bid Security detailed above. It shall be understood that the tender documents have been issued to the tenderer and the tenderer is permitted to tender in consideration of stipulation on his part, that after submitting his tender he will not resile from his offer or modify the terms and conditions thereof in a manner not acceptable to the Engineer. Should the tenderer fail to observe or comply with the said stipulation, the aforesaid amount shall be liable to be forfeited to the Railway.If his tender is accepted, this Bid Security mentioned in sub para (a) above will be retained as part security for the due and faithful fulfillment of the contract in terms of Clause 16 of the Standard General Conditions of Contract. The Bid Security of other Tenderers shall, save as herein before provided, be returned to them, but the Railway shall not be responsible for any loss or depreciation that may happen thereto while in their possession, nor be liable to pay interest thereon.
  Show more

• Price variation clause As per GCC-April-2022.

• Tenderer may opt for Letter of Credit as a mode of payment in terms of railway Board letter no. 2018/CE-I/CT/9, dtd 04.06.2018

• It may be noted here that the conditions of Indian Railways Standard General Conditions of Contract with up to date correction slip of S. E. Railway, all provisions of relevant codes, manual etc.( with the latest amendment, if any), are generally applicable unless specifically mentioned otherwise in this paper/in the special conditions of contract, additional special condition of contract, tender schedule and technical specification. The intending tenderer before submission of tender is advised that in his own interest to study the tender papers carefully without prejudice to the generally of the foregoing and the tenderer shall inspect the site and surrounding of the works specified in the tender documents and shall satisfy himself by careful examination before submission of the tender as the nature of site , soil and local conditions, availability of labour and materials for execution of work, the means of access to site supply of power, water, availability of accommodation etc. and shall make local and independent inquiries as to matters for and things referred to or implied in the tender documents. Railways shall not entertain the tenderer in any form or plea of ignorance, difficulties doubts, misconception and mis-appreciation thereof effecting the execution and completion of work.

  Show more

• Employment/Partnership etc. of Retired Railway Employees:As per condition mentioned under GCC-APRIL-2022.

• The instant tender is governed as per GCC-April-2022 with all latest updates/correction slips.

The purchasers approval will be based on these considerations .

Special Conditions

• The contractor will have to carry out the detailed site- survey for the assessment of the quantity of materials along with its character, quality, type/style, size in detail of the materials to be encountered. After assessing the requirement of material as per site, the contractor should place order for procurement of all materials within fifteen days of approval of plan of action in Bar-Chart as per schedule of work/or as per instruction of the Railway, if any and purchase order copy of materials should be submitted to Sr. DEE/TRD/ADRAs office, accordingly.

• Firms which have not migrated to GST regime and are not registered for GST will not be able to participate in any tender of this Railway. Any offer received from the firms without GST registration will be summarily rejected.

• 1. Tenderer has to submit the bill in terms of Railway Board letter no. 2016/CE-I/CT/12/GST/ Pt .1 dt.29.6.2017 and to follow the subsequent instructions to be issued by Railway Board for the compliance of GST.
  2. Amendment in Clause 46A, Part-II of Indian Railway Standard General Conditions of Contract, July'2014- Price Variation Clause as per Railway Board's letter no. 2017/CE-I/CT/4/GST dated 05.07.17 shall be binding upon the Contractor.
  3. Tenderer must have valid PF code number. Tenderer should upload document with respect to valid PF code number. Bill will be cleared only after verification of PF challan paid for previous month along all other statutory dues by the contractor/ establishment.

• The Tenderer shall submit along with Tender document, documents in support of his/their claim to fulfill the eligibility of Criteria as mentioned in the Tender document. Each page of the copy of documents/certificates in support of credencials, submitted by the tenderer, shall be self attested/digitally signed by the tenderer or authorized representative of the tendering firm. Self attestation shall include signature, stamp and date (on each page). Only those documents which are declared explicitly by the tenderer as "documents supporting the claim of qualifying the laid down eligibility Criteria", will be considered for evaluating his/their tender The Tenderer shall submit a certificate in the prescribed format (please download the format from the link given below) for verification / confirmation of the documents submitted for compliance of eligibility / qualifying criteria. Non submission of the certificate, or submission of certificate either not properly filled in, or in a format other than the prescribed format shall lead to summary rejection of your offer. (Click here to download the Format of Self Certification).

  Show more

• The Railway reserves the right to verify all statements information and documents submitted by the bidder in his tender offer and the bidder shall, when so required by the Railway, make available all such information, evidence and documents as may be necessary for such verification. Any such verification or lack of such verification, by the Railway shall not relive the bidder of its obligations or liabilities here under nor will it affect any rights of the Railway there under. b) In case of any wrong information submitted by the Tenderer, the contract shall be terminated, Bid Security, Performance Guarantee (PG) and security deposit (SD) of contract forfeited and agency barred for doing business on entire Indian Railways for 5 (Five) years.

• A. Contractor is to abide by the provision of payment of Wages act & Minimum Wages act in terms of clause 54 & 55 of Indian Railways General Condition of Contract. In order to ensure the same, an application has been developed and hosted on website 'www.shramikkalyan.indianrailways.gov.in'. Contractor shall register his firms/company etc. and upload requisite details of labour and their payment in this portal. These details shall be available in public domain. The Registration/updation of Portal shall be done as under:

• (a)Contractor shall apply for onetime registration of his company/firm etc. in the Shramikkalyan portal with requisite details subsequent to issue of Letter of Acceptance. Engineer shall approve the contractor's registration on the portal within 7days of receipt of such request

• (b)Contractor once approved by any Engineer, can create password with login ID (PAN No.) for subsequent use of portal for all LOAs issued in his favour

• (c)The contractor once registered on the portal, shall provide details of his Letter of Acceptance (LoA)/ Contract Agreements on shramikkalyan portal within 15 days of issue of any LOA for approval of concerned engineer. Engineer shall update (if required) and approve the details of LOA filled by contractor within 7 days of receipt of such request

• (d)After approval of LOA by Engineer, contractor shall fill the salient details of contract labours engaged in the contract and ensure updating of each wage payment to them on shramikkalyan portal on monthly basis

• (e) It shall be mandatory upon the contractor to ensure correct and prompt uploading of all salient details of engaged contractual labour & payments made thereof after each wage period

• While processing payment of any bill or release of Performance Guarantee/ Securiy depoist', contractor shall submit a certificate to the Engineer of Engineer's representatives that "I have uploaded the correct details of contract labour engaged in connection with this contract and payments made to them during the wage period in Ralway's Shramikkalyan portal at 'www.shramikkalyan.indianrailways.gov.in'till______Month,______Year

• The tenderer should go through all conditions mentioned in the NIT along with Annexures (I,II,III and IV) as attached minutely prior to bidding.

• The Railway will not provide any drawings/specifications etc. required in connection with the execution of work as mentioned in the tender document. The contractor has to arrange all drawing and documents at his own cost from the office of CORE/RDSO or Sr.DEE/TRD/ADAs office on payment.

• All materials to be supplied by the contractor have to be duly inspected by RITES or a Competent Railway official as appointed by Sr.DEE/TRD/ADA. No payment will be made unless the inspection certificate has been submitted along with Manufacturers original challans and test certificates. The materials have to be procured only from CORE/RDSO approved sources wherever applicable.

• The Railway has the right to supply any item if available with the railway even though it is covered under the scope of supply by the contractor. The quantities to that effect will be reduced from the scope of supply accordingly.

• Any work falling under power block will be determined by the Railway Engineer and the power blocks will be arranged by the Railways supervisor. The contractor has to work with minimum power block with adequate arrangement of manpower, tools & plants and materials as decided by the Railway and penalty can be imposed to the contractor for exceeding of the arranged power block in a particular type of work or for not arranging adequate manpower, tools & plants and materials. Any dispute in this regard each only be decided by Sr.DEE/TRD/ADA and his decision will be final and binding on the contractor.

• The cost incurred in carrying out cube test for concrete foundation sample shall be borne by the contractor.

• Variation in the contract will be governed as per Rly. Model SOP-2018 and as per GCC.

• The tenderer should survey the site/location and get himself acquainted with all the details site conditions before making the offer.

• The LD Clause will be applicable in Phase wise both for non-completion of work as detailed in the plan for execution of the job and non-supply of materials by the tenderer/contractor in time as per GCC.

• If there is any item which is not covered by the special conditions of contract or by the terms and conditions mentioned elsewhere in the tender, the terms and conditions mentioned in the General Conditions of Contracts with latest amendment if any, applicable to works contract of S.E. Railway shall apply. In case there is any condition between special conditions and General Conditions of Contract, the special conditions of contract shall prevail.

• The following documents should be specified for submission along with tender:-

  1. List of personnel organization available on hand and proposed to be engaged for the subject work.
  2. List of Plan and machinery available on hand (own) and proposed to be inducted (own and hired to be given separately) for the subject work.
  3. List of work completed in the last three financial years giving description of work, organization for whom executed, approximate value of contract at the time of award, date of award and date of schedule completion of work. Date of actual start, actual completion and final value of contract should also be given.
  4. List of works on hand indicating description of work contract value, approximate value of balance work yet to be done and date of award. NOTE:
     1. In case of items (c) and (d) above, supportive documents/ certificates from the organization with whom they worked/are working should enclosed
     2. Certificate from private individuals for whom such works are executed/being executed should not be accepted.
  Show more

• Decision of Sr.DEE/TRD/ADA regarding minus and / or plus variation as per the Railways requirement will be final and binding on the contractor as governed by SOP-2018 and GCC.

• Any instructions issued by the Railway from time to time regarding payment of wages to labour will be adhered to by the contractor and Decision of Sr.DEE/TRD/ADA regarding this will be final and binding on the contractor.

• Whenever an item of work covers supply of materials/erection/installation etc such item will include supply of all associated accessories (such as bolts, nuts, washer of GI & SS clamps, foundation bolts etc or any other ancillary materials as per CORE/RDSO latest specification and drawings) which will be required to complete the work in all respect as per site condition to the satisfaction of Railway as well as to maintain the relevant standard, code of practice ensuring safe working. No separate payment for fastener is admissible.

• Erection/Installation of equipment (in respect of supply either by Railway or by the contractor) will include testing, satisfactory functioning as well as detail briefing regarding erection/maintenance/periodical schedules etc for the beneficial use of the Railways, such briefing will include as necessary with four copies of drawings literature/notes/operating manuals/maintenance manuals etc. on demand by the Railways. (b)The basic quantity of components and materials require to make up a unit of work for the selected items are indicated for guidance only. There may be minor variation to suit erection but no adjustment in prices shall be made on that account.

• The tenderer should read the tender schedule along with explanatory notes under technical compliance in respect of the work and site condition carefully and seek clarification if any before submitting the tender paper. No clarification/dispute will be entertained afterwards. Any clarification/disputes after opening of tender in this regard will be decided by Sr.DEE/TRD/ADA and his decision shall be final and binding on the contractor.

• Offers are to be submitted as per GST regime. Tender should carefully understand the tender schedule along with explanatory notes under Technical compliance and inspect the site to satisfy himself in all respect to complete the project/work before submitting the offer. After submission of offer it will be deemed that the contractor has understood the project/work and will complete the project/work at the quoted rate. It is understood and agreed that the contractor has, by carefully examination, satisfied himself as to the nature and location of the work, the conformation of the ground, the character, quality and quantity of the materials to be encountered, the character of equipment and facilities needed preliminary to and during the progress of the works, the general and local conditions, the labour conditions prevailing therein and all other matters which can in any way affect the works under the contract.

  Show more

• The rates entered in the accepted schedule of rates of the contract are intended to provide for works duly and properly completed in accordance with general and special (if any) conditions of the contract and the specifications and drawings together with such enlargements, extensions, diminutions, reductions, alterations or additions as may be ordered in terms of clause 42 of G.C.C and without prejudice to the generality thereof.

• All the machines, components, equipment (including ancillary parts/components) shall be of RDSO/CORE approved sources and wherever any items are not covered under RDSO/CORE approved list of vendor it should be of reputed make/brand subject to prior approval to be obtained from Sr.DEE/TRD/ADA before its supply irrespective of such stipulation mentioned against the items in the schedule or not.

• Machines/Components/Equipments shall be as per relevant Railway specification and where Railways specification is not available relevant IS specification to be observed.

• All the works shall be carried out duly observing the relevant standard/code of practice, IR rules and specification and drawings approved by Railways. The successful tenderer on receipt of the LOA and after observing all the basic formalities must provide a detailed planning for the execution of work with time limit and got the approval before commencement of work.

• The tenderer shall go through special condition and Explanatory notes under Technical compliance for schedule items thoroughly before submitting offer.

• The work for - "OHE work for provision of Two New full length line approx. 750 mtr. One common loop in UP direction and One in DN direction at Chhatna station in Adra division..". "As soon as The Letter of Acceptance (LOA) is issued, the contractor should carry out the detailed survey of work-site spreaded over ADRA Division and should prepare and submit plan of action in Bar-Chart for which location nos. /name of sections shall be provided by the Railway along with the LOA . The said plan of action in Bar-Chart for execution of work at locations /sections should be submitted to Sr. DEE/TRD/ADRA's office for its approval within first fifteen days of issue of LOA

• After submission of the said plan of action in Bar-Chart, the Railway will scrutinize the same and necessary approval will be given on the plan of action in Bar-Chart fifteen days of its submission.

• The contractor should make preliminary arrangement for execution of work immediately after issue of LOA and should start the work immediately after approval of plan of action in Bar-Chart.

• Procurement action of the materials should invariably be in accordance with requirement of site i.e. it must be ensured by the contractor to supply materials earliest which will be required at first in course of execution of work.

• All the materials duly inspected should be supplied within two months from the date of approval of plan of action in Bar-Chart

• Any delay in submission of plan of action in Bar-Chart for approval or in supply & delivery of materials shall be recorded in your performance for future necessary action.

• The LD Clause will be applicable in Phase wise both for non-completion of work as detailed in the plan for execution of the job and non-supply of materials by the contractor in time.

• The contractor shall have to deploy one of his representatives for making liaison for power block planning and execution of work for which he will have to consult with CTPC/ADRA one day in advance for power block of the next day .

• The contractor shall have to deploy their men and materials at three work site simultaneously in order to finish the work in time .Similarly, the contractor will have to undertake the work section-wise as per plan and programme for which Tower wagon will be provided by the Railway.

• The work should be completed within stipulated completion period as per tender notification.

The balance sheet and all other financial documents attested /certified by CAs to substantiate fulfilment of Financial Eligibility criteria should be with UDIN, failing which the offer is likely to be rejected without any further reference.

Technical-Compliances

• Explanatory notes on Schedule-I item No.1:-Supply of rolled or fabricated and galvanized traction masts, auxiliary transformer masts, Feeder mast- The price shall cover the cost for supply of traction mast, auxiliary transformer masts, Feeder mast to be procured from CORE/RDSO's approved suppliers only conforming to latest CORE/RDSO's approved drawings and specifications. The type of mast will be as per approved design and the supply will be made on written order of Sr.DEE/TRD/ADRA. The price shall also cover the cost for supply of main masts whether rolled or fabricated including those for head span, fabricated structure etc. Note for measurements: For the purpose of payment, the weight of individual traction mast and masts of head span shall be determined for each type on the basis of the payable weights per meter length as shown in Annexure-I for standard types or as per inspection report as authorized by Railway. . For special types, the payable weight per meter length will be indicated by the purchaser at the time of approval of designs .

  Show more

• Explanatory notes on Schedule-I item No.2:-Supply of TTC Structures and Portals with boom:-The materials should be supplied from CORE/RDSO approved suppliers only. The price shall cover the cost for supply of TTC structures complete with upright, boom, knee plate and all type of fasteners conforming to the latest CORE/RDSO's drawing/specification and procured from approved source. The price shall also include the cost of supply of portals complete with uprights, boom pieces, knee bracing, cover angles and all type of fasteners conforming to latest CORE/RDSO drawing/specification and procured from approved sources. Supply will be made on written order of Sr.DEE/TRD/ADRA. Payable weight shall be as per Inspection report as authorised by Railway.

• Explanatory notes on Schedule-I item No.3:-Supply of fabricated and galvanised steel work other than traction mast (SPS). - The materials should be supplied from CORE/RDSO approved suppliers only. The price shall cover the cost for supply of all fabricated steel and mast fitting for hook insulator and mast bracket fitting assembly for attachment to the structure for erection of cantilever. For standard fabricated steel work for which RDSO approved drawings are available, the weight of steel work as specified in RDSO drawings shall be considered for payment. However, in case the unit sectional weight of any member indicated in RDSO drawing is not in conformity with the unit sectional weight as per the latest IS specification, the weight of the fabricated steel work shall be calculated on the basis of latest IS specification and the same will be considered for payment. For the non-standard fabricated steel work, the calculated weight to be considered for payment under this item shall be included in the relevant drawing based on, latest IS sectional weight at the time of submitting the designs for approval of the purchaser. The prices shall also include supply of galvanized bolts, U bolt, nuts washers etc. wherever required as per approved designs and drawings. The price shall cover supply, fabrication of arrangements for mounting of traction mast on bridge piers/girder. Notes for measurement:-

  1. For purpose of payment against items 3 the weight of structures of fabricated steel work will be calculated according to the weight of black steel given in section books for the lengths of various members shown in the approved drawings. There will be no addition for increased weight due to galvanizing or painting or weld material or reduction for holes or skew cuts.
  2. Unless specifically indicated none of the other items of work shall include the cost of supply and/or erection of small part steel work which will invariably be paid for under item 3 as applicable
  Show more

• Explanatory notes on Schedule -I item no.4:- Supply of single cantilever assembly complete with insulator for conventional OHE- The Price shall be on a flat rate basis of any bracket assembly of CORE/RDSO approved make on traction masts or support on drop arm and shall include those on high/ low level platform in the vicinity of turnout over bridges or overlaps and at location with reduced encumbrance or terminating wires. The materials should be supplied from CORE/RDSO approved suppliers only. The price shall include the cost of supply of all components including galvanized steel tubes conforming to latest CORE/RDSO specification and complete with bolts and nuts etc if any, and with inspection of all items as per instruction of Railway,, with stay insulators, bracket insulator. Single bracket assembly generally consists of the components as indicated in Annexure-III and components of a cantilever assembly shall be as per work site requirements/ approved Drawing. Price shall also include the cost of supply of forged steel OHE fittings/ components pertaining to Single Bracket assembly wherever required as per instruction of Railway. The price also includes the cost for supply of all necessary accessories required for its erection including packing sadle for each cantilever.

  Show more

• Explanatory notes on Schedule-I item No. 5:- Supply of guy rod assembly- The price covers the cost of materials to be supplied from CORE/RDSO approved suppliers only. The price shall also cover the cost for supply of guy rod assembly of various length of traction mast, feeder mast or supports complete with mast guy rod fittings, guy rod with adjustment and parts to be grouted in anchor block.. Guy rod assembly generally consists of components as indicated in Annexure-II and components of a Goy Rod assembly shall be as per work site requirements/ approved Drawing.

• Explanatory note for Schedule- I item No.6:- Supply of regulating equipment, 3 (three) pulley type, with all accessories including counter weight assembly, SS wire rope for conventional OHE- The price covers the cost of materials to be supplied from CORE/RDSO approved suppliers only. The Price shall cover the cost for supply of counter weight assembly including 9T adjuster with double strap assembly, Mast anchor fitting assembly (for modified 3: 1 ratio three pulley type regulating equipment) and normal/anti theft guide tube assembly, the supply of regulating equipment ( Modified 3: 1 ratio three pulley type) , Hex pipe of suitable length and stainless steel wire rope required for the regulating equipment, extra Anchor attachment, Guide tube fittings and small part steel work as well as associated fasteners as per requirement.

• Explanatory note for Schedule -I item No.7:- Supply of materials for termination of double conductor (including supply of cut-in insulator) of overhead equipment.- The materials should be supplied from CORE/RDSO approved suppliers only. The price shall cover the cost for supply of all materials necessary for the termination of double conductor of overhead equipment on a traction mast or structure including appropriate mast anchor fitting, clevis assembly, adjusters as per site requirement, anchor double straps, ending clamp, Double eye distance rod, equalizing/compensating plate required for catenary or contact wire or terminating wire and fitting and required insulators (cut in insulator).

• Explanatory note for Schedule -I item No.8:- Supply of materials for termination of a single conductor (including supply of cut-in insulator) of OHE or a terminating wire- The price shall cover the cost for supply of all materials to be supplied from CORE/RDSO approved suppliers only. Price shall cover the cost for supply of all materials necessary for the termination of single conductor of overhead equipment or terminating wire, including required insulator, on a traction mast or structure including appropriate mast anchor fitting clevis assembly, adjuster, anchor double straps, Insulator, ending clamp for catenary or contact wire or terminating wire and fitting . Note for measurement:- In case of V type anchorage is adopted for terminating a single conductor such an arrangement would be counted as 2 off under item 7 & 8 for the purpose of payment.

• Explanatory note for Schedule-I item No.9- Supply of OHE, excluding supply of catenary, contact, jumper, dropper wire and large span wire which will supplied by Railway.. - The Price shall cover the cost of materials to be supplied from CORE/RDSO approved suppliers only. The price shall cover the cost for supply of all components as per site requirement including dropper clips with bolts, nuts etc. , parallel clamps for Jumpering, Contact wire ending clamp, Catenary ending clamp, Large span wire clamp, Adjuster, Anchor double strap assembly, Compensating plate/equalizing plate and splices (where their use is approved),Note for measurement of item No. 9--For the purpose of payment against item, the length of overhead equipment, which shall include terminating wire, shall be measured form the center line of the traction mast/structure at which two ends of each tension length of OHE are anchored. The length shall be the difference between the actual chainage of the two traction masts/structures at which the ends of each tension length are anchored or by the sum of the actual span between the same two points whichever is higher as included in the as erected layout plan. For purpose of progress payment reference to layout plans as approved shall be made.Overhead equipment generally consists ofCatenary Splice- 6 nos. contact Splice- 2 nos. Catenary Ending Clamp- 4 nos. Contact Ending Clamp-2 nos. L.S. Wire Ending Clamp- 4 nos. P.G. Clamp - 1031-3- 10 nos. P.G. Clamp - 1041-26 nos. P.G Clamp-1051-4 nos. Catenary dropper clip with SS nut & bolt, washer & split pin-120 nos. Contact dropper clip- 120 nos. Double Strap-8 nos. 9 Tonne Adjuster (Forged)-4 nos.for per TKM. The quantity or requirement of materials may vary as per instruction of railway represnetative.

  Show more

• Explanatory note for Schedule -I item No.10:-Supply for additional, fittings at a turnout/crossings/overlaps.- The materials should be supplied from CORE/RDSO approved suppliers only. The price shall cover, on flat rate basis, supply of additional components and fittings required' at turnout/ crossovers/ overlaps (insulated or un-insulated) including overlaps knuckle or crossing equipment at a turnout, or a diamond crossing and parallel clamps/bimetallic parallel clamp for jumper connections between two sets of overhead equipment conductor at a turnout, diamond crossing, overlaps or neutral section,.Note for measurement item 10: A crossover shall be paid as 2 off of item 10, special configuration of OHE commonly known as half overlap shall be paid for as 1 off under this item. This shall apply in case of half overlap used in changing over from regulated to unregulated equipment or unregulated to regulated equipment.For purpose of progress payment reference to layout plans as approved shall be made.Additional, fittings at a turnout/crossings/overlaps consist of following materials on per TKM basis,Contact Wire Parallel Clamp with GI fastener (Large) {1031-3}- 8 nos.Contact Wire Parallel Clamp with GI fastener (Large) (1041-3}- 8 nos.Catenary wire dropper clip (1192)- 8 nos.Contact wire dropper clip (1180)- 8 nos.

  Show more

• Explanatory note for Schedule-I item No.11:- Supply of anti-creep with Railway supply catenary wire:-The price shall cover the cost of materials to be supplied from CORE/RDSO approved suppliers only. Price shall cover the supply of all materials for anti creep including adjusters (RI No. 5020) mast anchor fittings (RI 3231) with bolts and nuts etc at its termination on either side on structure ending clamps and other fittings viz 18 mm, single clevis assembly (RI 5040/3010), anchor double strap assembly (RI 5030), double suspension clamp (RI 1170), double eye distance rod (RI 5183) & two insulators but excluding anti-creep wire. Anti-creep wire for anti creep will be supplied by Railways.

• Explanatory notes on Schedule-I item No. 12:-Supply of structure bonds (other than platform)-The materials should be supplied from CORE/RDSO approved suppliers if any or as per instruction of Railway.. The price shall cover supply of structure bond made of 40 x 6 mm Mild steel flats duly fabricated having average length of 2.75 meter (length of different sizes as per site requirement may vary from 2.5 to 3m) Supply with fabrication of structure bond shall be done as per Railway drawing no ETI/OHE/7000 (Style-01) with the latest amendment if any or as per any other approved drawings of the Railway including painted with one coat of red oxide primer and final coat of Black Bitumin paint. The price shall also include the cost of all necessary fasteners (i,e suitable 2 (two) sets of GI bolt, nut, spring and flat round washer (16X50X38mm), lock nut, check nut etc) for erection of sstructure bond .

  Show more

• Explanatory notes on Schedule-I item No.13:-Supply of structure bonds ( on platform)-The materials should be supplied from CORE/RDSO approved suppliers only or as per instruction of Railway. The price shall cover supply of structure bond made of 40 x 6 mm Mild steel flats duly fabricated having average length of 4.75 meter (length of different sizes as per site requirement may vary) Supply with fabrication of structure bond shall be done as per Railway drawing no ETI/OHE/7000 (Style-01) with the latest amendment if any or as per any other approved drawings of the Railway including painted with one coat of red oxide primer and final coat of Black Bitumin paint. The price shall also include the cost of all necessary fasteners (i,e suitable 2 (two) sets of GI bolt, nut, spring and flat round washer (16X50X38mm), lock nut, check nut etc) for erection of structure bond .

• Explanatory notes on Schedule-I item No. 14:-Supply of Retro reflective Structure Number plate- Materials to be supplied from CORE/RDSO approved suppliers only. Price shall cover the cost for supply of Retro-reflective Structure Number Plate conforming to RDSO drawing No.ETI/OHE/P/7503 Rev A with the latest amendment if any, to be provided on traction mast or structures. The price includes the cost of Supply of nuts, bolts, Clamps, washers or any necessary material required for its erection.

• Explanatory notes on Schedule-I item No. 15:- Supply of 25 kV suspension 9 ton Insulator with suspension arrangement.-Materials to be supplied from CORE/RDSO approved suppliers only.The price shall cover the cost for Supply of 25 kV suspension 9 ton Insulator with suspension arrangement for suspension of aluminum/copper 25 kvconductors(130/64 sq.mm) or 65 sq.mm overhead equipment conductor or19/2.79 mm all aluminum catenary or any other similar type of suspension. The price shall cover supply of all components required for the suspension assembly including the appropriate suspension clamp and the 9 ton insulator assembly.

• Explanatory notes on Schedule-I item No. 16-Supply of 25 KV solid core cut-in-insulator assembly ( Porcelain)--.- Materials to be supplied from CORE/RDSO approved suppliers only. The price shall cover the cost for Supply of 25 KV solid core cut-in-insulator assembly ( Porcelain). The price shall cover supply of all components as required for its erection.

• Explanatory note for Schedule-I item No. 17:-Supply of MS flat for earth (50mm X6mm).-Supply of MS flat for earth (50mm X6mm).- The price shall cover the cost for Supply of Earth leads 50mm x 6mm mild steel laid in the ground. The materials should be supplied from CORE/RDSO approved suppliers or as per instruction of Railway . The price shall cover supply per meter length of 50x6 mm mild steel flat painted all around with two coats of painting to colour grass green shade-218 of IS:5 passing through cable trench or exposed above ground level. The price shall include the cost of necessary materials i.e. primers & paint required for painting. The price includes the cost of nuts, bolts, washers or any necessary material required for its erection.

• Explanatory note for Schedule-I item No.18:- Supply of 25KV single pole isolator without earth contact assembly..- The Price shall cover the cost of materials to be supplied from CORE/RDSO approved suppliers only. The price shall cover supply of 25 KV single pole isolator switch complete with arcing horns, operating rods, operating rod guides, mounting base and integral locks, Post insulator & Operating rod insulator, ALCU strips etc. Excluding earth contact assembly , The price also covers the supply of isolator number plate of approved design for each isolator. Price shall include supply of materials for making jumper connection with OHE excluding supply of jumper wire.

• Explanatory notes on Schedule-I item No.19-:-Supply of Transverse, Cross or Spl.bond.-Supply of Transverse bond, cross bond &Spl. bond :- The materials should be procured as per instruction of Railway only. The price shall cover the supply and fabrication of 40 x 6 mm. Mild steel flats required to provide transverse bond, cross bond & special bond connecting 2 (Two) rails at the rail joint at the locations to be specified by the Railway. Transverse bond, cross bond & special bond of different sizes (length of different instruction of Railway representatives. No.

  1. ETI/OHE/P/7000 (Style-1) or
  2. ETI/OHE/VI/0525 ( Style-02) / or and
  3. ETI/OHE/P/7030 ( Style-02) or as per any other approved drawings of the Railway including painted with one coat of red oxide primer and final coat of Black Bitumin paint. Average length of each bond shall be 2.75m including one place insulation where cross of the positive rail of track circuit. The price shall also include the cost of all necessary fasteners ( i.e. suitable 2 (Two) sets of GI bolt, nut, spring and flat round washer ( 16x50x38mm), lock nut, check nut etc) for erection of transverse bond, cross bond & special bond.
  Show more

• Explanatory notes on Schedule-I item No.20-:-Supply of Longitudinal bonds :- The material should be supplied from CORE/RDSO approved suppliers or as per instruction of Railway. The price shall cover supply of all materials including 40 x 6 mm mild steel flats, fasteners etc. required to provide longitudinal bonds connecting rails of the same /adjacent tracks at the locations to be specified by the Railway . The price shall also cover providing of special bonds at a level crossing, foot over/ road over bridge/protective screen etc. for with the location will be specified by the Railway. Longitudinal bond of different sizes (length of different sizes as per site requirement may vary from 1.5 m to 2.0 m ) will be fabricated by the tenderer as per instruction of Railway representatives. No.

  1. ETI/OHE/P/7030 (Style-1) or
  2. ETI/OHE/P/7030 ( Style02) or as per any other approved drawings of the Railway including painted with one coat of red oxide primer and final coat of Black Bitumin paint. Average length of each bond shall be 1.75 m. The price shall also include the cost of a 11 necessary fasteners ( i.e. suitable 2 (Two) sets GI bolt, nut, spring and flat round washer ( 16x50x38mm), lock nut, check nut etc) for erection of Longitudinal bond.
  Show more

• Explanatory notes on Schedule-I item No.21:- Supply and erection of Caution board for 25KV AC traction in 3 language English, Hindi and Bangla for traction use..- The Price shall cover the cost for supply and erection of Caution board for 25KV AC traction in 3 language English, Hindi and Bangla to be provided on traction mast or structures. price shall cover the cost for supply of all materials to be supplied from CORE/RDSO approved suppliers conforming to CORE/ RDSO drawing with the latest amendment if any, Price includes the cost for nuts, bolts and other necessary ancillaries required for its erection.

• Explanatory notes on Schedule-I item No.22:- Supply and erection of Danger board for 25KV traction use.- The price shall cover the cost for supply of all materials to be supplied from CORE/RDSO approved suppliers only. Price shall cover the cost for supply and erection of Danger board for 25KV traction use.

• Explanatory notes on Schedule-I item No.23:- Supply and erection of Unwired turn out Board for traction use..-The price shall cover the cost for supply of all materials to be supplied from CORE/RDSO approved suppliers only. price cover the cost for supply and erection o f Unwired turn out Board to be provided at Turnout Points or as per instructions given by the Railway.

• Explanatory notes on Schedule-I item No.24:- Supply and erection of Sectioning Diagram board .:--The materials should be supplied from CORE/RDSO approved suppliers only or as per instruction of Railway The price shall cover the cost for supply of Sectioning Diagram board as per standard indicating sectioning/power supply arrangement/different elementary sections/switches/Interrupters in different colours for the portion of OHE required to be depicted at cabins of SM office/Control Posts or as per instruction of Railway.

• Explanatory note for Schedule- I item No 25- Supply of 25kV Support/post Insulator.- Materials to be supplied from CORE/RDSO approved suppliers only. The price shall cover the cost for supply of 25 KV Support/post Insulator to support copper or aluminium jumper/bus-bars. The price shall cover supply of all components and fittings / angle iron (outrigger) to support the jumpers. It shall include supply of fixing bolts, nuts, lock nuts, washers and studs etc.

• Explanatory note for Schedule- I item No 26 :-Supply of Section Insulator assembly including cut in insulator:-The Price shall cover the cost of materials to be supplied from CORE/RDSO approved suppliers only. The price shall cover cost for supply of all components required for a standard section insulator assembly including special arrangement for supporting the equipments and terminal fittings for conductors and the section insulator assembly including section insulator number tag, etc (Adjustable dropper wire will be supplied by Railways) including supply of core & cut-in-insulator.

• Explanatory notes on Schedule-I item No. 27:-Supply & erection of Anti-climbing device for AT station:-The Price shall include the cost for supply of materials to be supplied from CORE/RDSO approved suppliers only or as per instruction of Railway. The price shall cover the cost of Anti Climbing Device as per latest RDSO/CORE drawing. The price also includes the cost for supply of Nuts, Bolts, clamps, Barbared wire and washers or any necessary material required for its erection. The price includes the cost of its erection along with all necessary materials required for its erection.

• Explanatory notes on Schedule-I item No. 28:- Supply of earth electrode-The Price shall cover the cost of materials to be supplied from CORE/RDSO approved suppliers only or as per instruction of Railway. The price shall cover supply of earth electrodes and its associated (viz. Sand , charcoal /coke, and salt etc. ) pertaining to earthing arrangement including fasteners like Nut , bolt , spring washers / lock nuts etc. and clamps/lugs suitable for directly connecting two mild steel flats of minimum size 50mm x 6mm of earth electrode as per approved drawing for such earthing arrangement of Railway or as per instruction of Railway . The price shall include the cost of necessary materials i.e. primers & paint required for painting .Supply of Nut , bolt and spring washers / lock nuts and other fasteners required for erection shall be also covered under this item. The price also includes the cost for supply box sump along with cover as per drawing .

  Show more

• Explanatory note for Schedule--I item No.29:-Supply of Splices for Catenary wire : -The Price shall cover the cost of materials to be supplied from CORE/RDSO approved suppliers only.The price shall cover the cost of supply of catenary wire splice required for splicing of terminated overhead equipment for extension .

• Explanatory note for Schedule--I item No.30:-Supply of Splices for Contact wire:-The Price shall cover the cost of materials to be supplied from CORE/RDSO approved suppliers only.The price shall cover the cost of supply of contact wire splice required for splicing of terminated overhead equipment for extension.

• Explanatory note for Schedule- I item No 31:-. Supply of approved soft & hard copy in 10 copies for existing station SWR. .-The sectioning diagram & Station working rule should be submitted in two copies for initial approval. After final approval 10 sets of hard copies & 01soft copy should be submitted to this office.

• Explanatory note for Schedule-II item No. 1:- Erection of rolled or fabricated and galvanizedtraction masts, auxiliary transformer masts, Feeder mast:- Erection price shall cover cost oferection, alignment and setting before grouting of individual traction mast, auxiliary transformermasts , feeder mast, main masts of switching and booster transformer stations and masts for LTsupply transformer stations, whether rolled or fabricated including those for head spans. Note :For the purpose of payment, the weight of individual traction mast and masts of head span shallbe determined for each type on the basis of the payable weights per meter length as shown inAnnexure-I for standard types or as per inspection report. For special types, the payable weightper meter length will be indicated by the purchaser at the time of approval of designs.

• Explanatory note for Schedule-II item No 2.:-Erection of TTC structures and portal with boom :-Erection price shall cover cost of erection, alignment and setting before grouting of individual TTCstructures and portal with boom. The work is to be done as per instruction of Railway. Payableweight will be as per inspection report or as per approval of Railway.

• Explanatory note for Schedule-II item No 3:- Erection of fabricated and galvanized steel work otherthan traction mast(SPS)- The price shall cover the cost of erection, alignment and setting beforegrouting, wherever required of portals, gantries, 2/3 tracks cantilever structures includingCantilevers and tower/steel work for feeders for traction substation, drop arms, standard supermastsand suspension brackets for feeders and return conductors, dwarf mast or stub masts foranchoring complete with anchor plates drilled and welded in position, multiple cantilever crossarm, chairs, adopters and attachments for bracket assemblies and all other small part steel works,the erection of which is carried out by the contractor irrespective of whether they are supplied bythe purchaser or the contractor. The prices shall also include erection of galvanized bolts, U bolt,nuts washers etc. wherever required as per approved designs and drawings. Notes formeasurement-For purpose of payment against item 3, weight of structures of fabricated steelwork will be calculated according to the weight of black steel given in section books for thelengths of various members shown in the approved drawings. There will be no addition forincreased weight due to galvanizing or painting or weld material or reduction for holes or skewcuts. (2) The rates against item 3 shallbe applicable to the erection of small part steel work, which are not covered under the variousother items of work. Unless specifically indicated none of the other items of work shall includeerection of small part steel work which will invariably be paid for under item 3 as applicable.

  Show more

• Explanatory note for Schedule-II item No 4--Erection of 150 sq mm hard drawn copper conductorfor feeder/return conductor 37/2.25 sq. mm..- The Price shall cover the cost for erection of 150 sqmm hard drawn copper conductor for feeder/return conductor 37/2.25 sq. mm. along with allcomponents and fittings required for its erection including P.G / ALCU Strips/ required clamps asper site requirement or as advise of Railway

• Explanatory note for Schedule-II item No 5--Erection of single cantilever assembly complete withinsulator for conventional OHE:-Price shall cover on a flat rate basis of erection of any bracketassembly (with its proper fabrication as per requirement at work site) on traction masts or supporton drop arm and shall include those on high/ low level platform in the vicinity of turnout overbridges or overlaps and at location with reduced encumbrance or terminating wires. Price shallcover erection of all components of single bracket assembly including solid core insulators anderection, fabrication of dropper wires .

• Explanatory note for Schedule-II item No 6:- Erection of guy rod assembly . - The price shall coverthe cost for erection of guy rod assembly of various length of traction mast, feeder mast orsupports complete with mast guy rod fittings, guy rod with adjustment and parts to be grouted inanchor block.

• Explanatory note for Schedule-II item No 7:- Erection of regulating equipment, 3 (three) pully type,with all accessories including counter weight assembly, SS wire rope for conventional OHE.- Theprice shall cover the cost for erection of counter weight assembly including 9T adjuster withdouble strap assembly, Mast anchor fitting and normal/anti theft guide tube assembly, regulatingequipment ( Modified 3 pulley type) and stainless steel wire rope required for the regulatingequipment and small part steel work, if any. The price shall also cover adjustment of the entireregulating equipment

• Explanatory note for Schedule-II item No.8:- Erection of materials for termination of doubleconductor (including cut-in insulator) of overhead equipment. - The price shall cover the cost forerection of all materials necessary for the termination of double conductor of overhead equipmenton a traction mast or structure including appropriate mast anchor fitting, clevis assembly, threeadjusters, anchor double straps, ending clamp, Double eye distance rod, equalizing/compensatingplate for catenary and/ or contact wire or terminating wires and fitting including 9 T insulator,terminating wire and insulators.

• Explanatory note for Schedule-II item No.9:- Erection of materials for termination of a singleconductor (including cut-in insulator)of OHE or a terminating wire. - Price shall cover the cost forerection of all materials necessary for the termination of single conductor of overhead equipmentor terminating wire, includingrequired insulator, on a traction mast or structure includingappropriate mast anchor fitting clevis assembly, adjuster, anchor double straps, ending clamp forcatenary and/ or contact wire or terminating wire and fitting including terminating wire and 9TInsulator .Note for measurement :- In case of V type anchorage is adopted for terminating a singleconductor such an arrangement would be counted as 2 off for the purpose of payment.

• Explanatory note for Schedule-II item No.10:- Erection of OHE including catenary, contact, jumper,dropper wireand large span wire which will supplied by Railway.- Price covers erection of allcomponents and wires and conductors including contact wire or catenary wire or both contact andcatenary wire as per work site requirement , droppers, jumpers including anti-theft jumpers andterminating wire, if any , dropper clips, parallel clamps for jumpering , Contact wire ending clamp ,Catenary ending clamp, Large span wire clamp, Adjuster , Anchor double strap assembly ,Compensating plate/equalizing plate and splices. The price shall also include the cost of paintingthe setting distance of mast/structure, contact height, rail level, temperature marking for counterweight movement , elementary section and location of emergency sockets on mast/structure. Noadditional payment will be made for manual stringing of conductor viz. catenary, contact wire etc.Note for measurement.:-For the purpose of payment against item 10, the length of overheadequipment, which shall include terminating wire, shall be measured from the center line of thetraction mast/structure at which two ends of each tension length of OHE are anchored. The lengthshall be the difference between the actual chainage of the two traction masts/structures at whichthe ends of each tension length are anchored or by the sum of the actual span between the sametwo points whichever is higher as included in the as erected layout plan. For purpose of progresspayment reference to layout plans as approved shall be made.

  Show more

• Explanatory note for Schedule-II Item No.11:-Erection for additional, fittings at aturnout/crossings/overlaps..- The price shall cover erection of all materials including jumper wire,insulators and all adjustments required at turnouts, crossings, overlaps and neutral sections. Theprice shall also cover erection of potential equalizer jumpers at insulated overlaps..Note formeasurement : A crossover shall be paid as 2 off of item11, special configuration of OHEcommonly known as half overlap shall be paid for as 1 off under this item. This shall apply in caseof half overlap used in changing over from regulated to unregulated equipment or unregulated toregulated equipment.

• Explanatory note for Schedule-II item No.12:- - Erection of anti-creep with Railway supply catenarywire ..- The prices shall include the cost for erection of all materials including 9 T insulatorassembly along with anti-creep wire or cadmium copper catenary wire as an anti- creep wire .Pricealso includes replacement of suspension clamp by double suspension clamp required for provisionof anti-creep. Payment shall be made on flat rate basis irrespective of length of anti-creep.

• Explanatory note for Schedule-II item No.13:- Erection of structure bonds (other than platform)-The price shall cover erection of structure Bond 40x6 mmwith required fasteners as per instructionof Railway representative. The price shall cover dismantling of the existing structure bond if anyas per instruction of Railway authorized representatives before erection of a new structure bond ifrequired as per site requirement . The price also included the cost of painting, shaping and drilling of thebond before erection as per instruction of Railway representative.

• Explanatory note for Schedule-II item No.14:-Erection of structure bond (on platform):-The priceshall cover erection of structure Bond 40x6 mm (on platform)with required fasteners as perinstruction of Railway representative. The price shall cover dismantling of the existing structurebond if any as per instruction of Railway authorized representatives before erection of a newstructure bond if required as per site requirement . All such dismantled materials shall be handedover to the purchaser's stores depot. The price also included the cost of painting, shaping anddrilling of the bond before erection as per instruction of Railway representative

• Explanatory note for Schedule-II Item No.15:-Erection of Retro reflective Structure Number plate--The Price shall cover the cost for erection of Retro-reflective Structure Number Plate to bemounted on OHE structure/gantry/wall as per CORE/RDSO approved drawing /or as perinstructions given by the Railway. The price shall include cost of erection of fasteners and fixtureson the masts also as per requirement at site.

• Explanatory note for Schedule-II item No.16:-Erection of 25 kV suspension 9 ton Insulator withsuspension arrangement.-The price shall cover cost of erection of a 9 ton suspension insulatorassembly including suspension arrangement for suspension of an all aluminium 25 kV feeder , 130sq.mm or65 sq.mm overhead equipment conductor or 19/2/79 mm all aluminium catenary or anyother similar type of suspension.

• Explanatory notes on Schedule-II item No.17:-Erection of 25 KV solid core cut-in-insulatorassembly ( Porcelain).- The Price shall cover the cost for erection of 25 KV solid core cut-ininsulatorassembly (Porcelain ).

• Explanatory notes on Schedule-II item No. 18:-Adjustment of OHE and Tower Wagon checking ofexisting OHE- The price shall cover the cost for adjustment and final checking of OHE by TowerWagon at each location with Railway Representative and each span for smooth running of electrictraffic and finally testing OHE & commissioning the same for which Tower Wagon will be providedby the Railway.

• Explanatory note for Schedule-II Item No.19:-Erection of MS flat for earth ( 50x6mm)- The Priceshall cover the cost for erection of Earth leads 50mm x 6mm mild steel laid in the ground as perinstruction of Railway Representative. The price also includes the cost for erection of Nuts, Boltsand washers or any necessary material required for its erection. The price also included the cost ofpainting, shaping and drilling before erection as per instruction of Railway representative

• Explanatory note for Schedule-II item No.20:- Erection of 25KV single pole isolator without earthcontact assembly.:- The price shall cover erection of a single pole isolator complete in all respectwith mounting base, operating rod, operating rod guide and operating rod insulator, post insulatorrequired for the operation of the isolator . The price shall also cover erection of ALCU strips, apadlock and a number plate of approved design for each isolator.. Necessary checks, tests andcommissioning shall be arranged by the contractor.

• Explanatory note for Schedule-II item No.21:- Erection of Transverse, Cross or Spl.bond.- The priceshall cover the cost for erection of Transverse, Cross or Spl.bondincluding all fastenings at bothends. The price shall cover dismantling of the existing bond if any as per instruction of Railwayauthorized representatives before erection of a new bond if required as per site requirement. Allsuch dismantled materials shall be handed over to the Railway's stores depot. The price shallinclude shaping, painting and drilling of the rail if required as per instruction of Railway.

• Explanatory note for Schedule-II Item No. 22:--Erection of longitudinal bonds- The price shall covererection of 40 x 6mm. Mild steel flat required to provide longitudinal bonds including all fasteningsat both ends. The price shall cover dismantling of the existing longitudinal bonds if any as perinstruction of Railway authorized representatives before erection of a new longitudinal bonds ifrequired as per site requirement. The price shall include shaping, painting and drilling of the rail ifrequired as per instruction of Railway.

• Explanatory notes on Schedule-II item No.23:-Erection of 25 kV Support/post Insulator.- The Priceshall cover the cost for erection of 25 KV Support/post Insulators to support copper or aluminumjumper/bus-bars. The price shall cover the cost for erection of all components and fittings / angleiron(outrigger) to support the jumpers. It shall include erection of fixing bolts, nuts, lock nuts,washers and studs etc.

• xplanatory note for Schedule-II Item No.24:- Erection of Section Insulator assembly including cutin insulator.- The Price shall cover the cost for erection and adjustment of all components ofsection insulator assembly including 9T insulators and shaping / installation of adjustable droppersas per instruction of Railway.

• Explanatory notes on Schedule-II Item No.25:-Erection, Testing & commissioning of 25kV/240VAuxiliary supply transformer with dropout fuse (10kVA capacity).- The price shall cover theerection of 10 KVA LT supply Auxiliary transformer complete with terminal connector on a mast organtry. The price shall be applicable for transformers mounted on steel pedestals at switchingstation also. The price shall cover the cost for erection of DO fuse assembly with the associatedarrangement . The price includes the cost of testing as per instruction of railway.

• Explanatory note for Schedule-II Item No.26-Erection of 42 kV, 10 KA metal oxide gapless typeLightning Arrestor as per RDSO specn.:-The Price shall cover the cost for erection 42 Kv LightningArrester along with all necessary accessories like CABLE, DICONNECTORS,SURGE MONITOR andINSULATING BASE. The Price shall also cover the cost for erection, anchors, fasteners, Nuts, Boltsand washers required for its installation and commissioning

• Explanatory notes on Schedule-II item No 27:-Erection of disconnector assembly kit for 42 kVLightning Arrestor as per RDSO specn..:- The price shall cover the cost for erection of disconnectorassembly of 42 kV LA along with all ancillaries.

• Explanatory notes on Schedule-II item No. 28:-Erection of earth electrode.- The Price shall coverthe cost for erection of earth electrode , as per directive of railway representative. price shallinclude the cost charcoal/coke, salt, sand etc. in proper quantity, price shall also include the costfor erection of two connecting mild steel flats of size50mm x 6mm . price also includes the costfor erection of fasteners like Nut ,bolt , spring washers / lock nuts etc. and clamps /lugs requiredfor connecting mild steel flats . The price also includes the cost for erection of box sump withcover and to be painted with black along the metal frame and lime coating over the box andcover, the earth value to be megared and to be mentioned over the box sump.

• Explanatory notes on Schedule-II item No.29:-Shifting/Transfer of OHE from one support to anotherand adjustment of droppers- The price shall cover the cost for transfer of overhead equipment ona new mast or support from the old mast or support and consequent adjustment to overheadequipment required such as respacing of droppers leveling etc.

• Explanatory note for Schedule-II item No.30:- Dismantling & removal of cantilever assembly - Theprice shall cover dismantling & removal of the existing cantilever assembly as per instruction ofRailway authorized representatives. All such dismantled equipment/materials shall be handedover to the Railway's' stores depot.

• Explanatory note for Schedule-II item No.31:- Dismantling & removal of OHE terminationassembly.-The price shall cover the cost for dismantling & removal of the existing OHEtermination assembly as per instruction of Railway authorized representatives.

• Explanatory note for Schedule-II item No 32- Dismantling & removal of Cutting of mast/TTC/portaluprights from ground level.-.- The Price shall cover Dismantling & removal of Cutting ofmast/TTC/portal uprights from ground level as per instruction of Railway authorizedrepresentatives, and remove the same without any damage and shifted them suitably so thatthere is no infringement in train movement. The work is to be executed under power block/nonpowerblock by contractor's labour, tools and tackles. All such dismantled equipment/materialsshall be handed over to Railway's stores depot.

• Explanatory note for Schedule-II item No.33:- Dismantling & removal of Guy Rod/Anchor assembly-The price shall cover dismantling of the existing Guy Rod/ Anchor assembly as per instruction ofRailway authorized representatives. All such dismantled equipment/materials shall be handedover to Railway's depot.

• Explanatory note for Schedule-II item No. 34:- Dismantling & removal of Anchor assemblyincluding regulating equip.- The price shall cover dismantling & removal of Anchor assemblyincluding regulating equipment as per instruction of Railway authorized representatives. All suchdismantled equipment/materials shall be handed over to the purchaser's stores depot.

• Explanatory note for Schedule-II item No.35:-Dismantling & removal of Small parts steel includingportal/TTC boom- Price shall cover Dismantling & removal of Small parts steel including portal/TTCboom as per instruction of Railway authorized representatives, and remove the same without anydamage and shifted them suitably so that there is no infringement in train movement. The work isto be executed under power block/non-power block by contractor's labour, tools and tackles. Allsuch dismantled equipment/materials shall be handed over to the Railway stores depot..

• Explanatory note for Schedule-II item No.36:- Dismantling & removal of Anti creep:-The price shallcover the cost for Dismantling& removal of Anti creep assembly as per instruction of Railwayauthorized representatives. All such dismantled equipment/materials shall be handed over to theRailway stores depot.

• Explanatory note for Schedule-II Item No.37:-Dismantling & removal of Isolator complete :- Theprice shall cover the cost for dismantling &removal of the existing isolator assembly as perinstruction of Railway authorized representatives. All such dismantled equipment/materials shallbe handed over to the Railway stores depot

• Explanatory notes for Schedule-II item No. 38:- Dismantling & removal of A.T. with D.O. fuse..-Theprice shall cover the cost for dismantling of the existing A.T with D.O fuse assembly along with itsassociated components as per instruction of Railway authorized representatives.

• Explanatory note for Schedule-II Item No 39-Dismantling & removal of Section insulator assembly-The price shall cover dismantling & removal of Section insulator assembly as per instruction ofRailway authorized representatives. All such dismantled equipment/materials shall be handedover to Railway stores depot.

• Explanatory note for Schedule-II item No.40:-Preparation of all drawing and design for over headequipment including preparation of pre-pegging, pegging and OHE layout plan:-Price shall coverthe following: -Survey of site and submission of drawings, LOP, Plan of action with Bar Chart forRailwaysapproval . The drawing and LOP should be printed in different coloured ink clearlyindicating all the details of existing OHE and modification works to be carried out. These should bein three sets. One set will be returned to Contractor duly approved for execution of work. -Preparation of cross section drawings (CSD) and structure erection drawings (SED) for individuallocation. - Choice of type and size of foundations with soil investigation. - Supply of drawings onapproval of drawings. 6 copies of CSD and SED shall be supplied for reference at field, office andTRD officials. - Preparation and supply of as erected drawings shall be one copy in original + 2 RTF+ 3 Ammonia prints + 1 soft copy in AUTOCAD as per instruction of Railway. NOTES FORMEASUREMENT :For the purpose of payment against this item, the length of track shall bemeasured as under :GENERAL:The difference in the chainage of the length under consideration, asincorporated in the layout plans in Km.

  2. TURN OUTS:The track taking off shall be deemed asstarting from the toe of the switch of the turnout.
  3. CROSS OVERS:The length of track shall betaken as the difference in the chainage of the toes of switches of the two turnouts constituting thecrossover.
  4. DIAMNOD CROSSING WITH OR WITHOUT SLIP:The two track crossing each othershall be measured independently as per note 1 above as though there were no crossing. No extrapayment for allowance shall be provided for slip points.
  5. DEAD ENDS AND TOP OF LOOPS: Thelengths for payment under this item shall up to the chainage of anchor mast of the terminatingOHE.
  Show more

• Explanatory notes for Schedule-II item No. 41:- Preparation & design of Station Working Rulecomplete in all respect of existing station:- The price shall cover site survey and preparation of alldrawings required for sectioning diagram and station working instructions/rule as per RDSO/COREstandards. The price shall also cover preparation /correction/ modification of the existing stationworking rule diagram and working instruction in consultation with purchaser. No extra paymentshall be made for modifications required to be done due to change in track centers, slewing oftracks and modifications in Engg. plans or due to changes in scheme by Railways. Themodification in SWR of adjacent stations shall also be done by contractor at his own cost. Thedesign of sectioning as per guidelines of RDSO/RB duly consulting Railway authority shall also bedone. Note: However, if SWR need to be changed due to commissioning of Yard in phased mannerthan payment shall be made for each phase if SWR need to be revised due to phasing if agreed byRailway representative

  Show more

• Explanatory note for Schedule-II item No.42:-Concrete for foundation& trench and brick work in alltype of soil including hard/rocky soil (Including excavation and supply of all materials viz. sand,cement and ballast etc.) trench.- The price will cover the cost of Concrete for foundation andplinth in all type of soil including hard/rocky soil (including excavation and supply of all materialsviz sand, cement and ballast etc.) The price shall cover excavation, supply and handling of allmaterials and accessories temporary arrangements for excavation, concreting and grouting thereafter including supply of cement, sand, ballast and other materials whatsoever. Price also includessupply and handling of arrangements for shoring and shuttering where necessary, casting,concrete, grouting of mast/structure and finishing the top of concrete foundations with muff. Pricealso includes dismantling of temporary arrangement and Removal and dressing of soil.

  Show more

• Notes for measurement of Schedule-II item No.42:-

  1. The rates per cubic metre (cum) under itemNo.42 shall be same 'for any shape or size of concrete blocks. In calculating the individual volumeof concrete, fraction of a cubic metre beyond the third decimal shall be rounded off to the nextnearest third decimal.
  2. The price shall apply for concreting of all foundation for mast, gantries,portals, anchor blocks for guy rods and fencing uprights, TTC, dwarf mast etc.
  3. For purpose ofcomputation of volume of concrete under item no. 42 the volume of steel work embedded in thefoundation block and shall be ignored.
  4. Cost of all concrete will be paid for only under Item no.42.
  5. For purpose of computation of volume of concrete under item no. 42 the volume Ofconcrete shall include the volume of sand and bitumen in sand cored foundation.
  6. For purposeof computation of volume of concrete the volume of each muff for all masts shall be taken as 0.02cum except for masts with balance weight and for each upright of portal, each head span mast, 2or 3 track Cantilever masts and special fabricated masts for which the volume of muff shall betaken as 0 .08 cum irrespective of the size and shape of muff on a flat rate basis.
  7. The price under item no.42 shall also include the cost of concrete for embedment of drain pipes where required.
  8. The prices under item no. 42 shall also cover the cost of concrete for diversion ofMasonry/earth drains wherever necessary for casting of foundation.
  9. Cement for use in theWork should be procured by the contractor from the main producers/their authorized dealers only.
  10. Cement bags should bear the following in formation in legible markings.
      1. Manufacturersname:
      2. Registered trademark of manufacturer, if any
      3. Type of cement
      4. Weight of each bag inkg.
      5. Date of manufacture, generally marked as week of the year/year of manufacture e.g.30/99which means 30th week of 1999.
      6. Grade of cement not less than 43.
  11. To ensure qualitycontrol, test certificate from the manufacturer should be produced by the contractors, whichshould conform to the relevant specifications (Latest may be incorporated).
  12. Railways may alsotake samples during the course of work and get the cement tested to ascertain their conformity tospecification.
  13. Concrete of foundation shall be nominal mix of grade M-10 obtained by mixingcement coarse aggregate, fine aggregate and water in accordance with table -3 of IS:456. Forgrouting, muffing, embedding of structure in foundation and for cable trench at switchingstations, normal mix concrete M-15 obtained by mixing materials in proportion as indicated intable 3 of IS :456shall be used. (Xiv) Cube test report: The contractor shall arrange concrete cubetest as per relevant BIS specification to be used in the foundation. The cost of cube test shallcarryout by the contractor for completion of each 50 Cu. M or its fraction for entire volume ofwork.
  Show more

• Explanatory note for Schedule-II item No.43:-Transportation of materials:- Transportation ofRailway supply materials ( traction masts and other OHE equipment) from Railways depot to siteof work & vice versa with lead.:- Price shall include the cost of transportation of all materialsissued/supplied by the Railway a n d the contractor has to make arrangement for transportation ofmaterials to work sites .The materials will be supplied/issued either from RRD/Adra or any otherlocations under jurisdiction of Railway depots of Adra Division. Price shall also include the cost oftransportation of released materials (and also its stacking at the location as per instruction ofRailway ) , from work site to the different OHE depots or RRD/ADA or as specified by the Railway .Transportation price shall cover loading /unloading of materials with lead. Transportation ofMaterials will be done as per instruction of Railway and in case of any dispute decision of Sr.DEE/TRD/ADA shall be final and binding on the contractor.

  Show more

• Explanatory note on power block Work under power block: Any activity under erection or dismantling work for schedule-II item no. 44, 45, 46, 47, 48, 49, 50, 51, 52, 53, 54, 55, 56, 57, 58, 59, 60, 61, 62, 63, 64, 65, 66, 67, 68, 69, 70, 71, 72 & 73 as per schedule if done under power block: The price under this items cover extra charges over and above erection or dismantling rates of such items for erection or dismantling of equipment in the vicinity of energized overhead equipment and feeders or erection or dismantling of equipment with joints equipment already energized or an energized equipment which calls for a power block (shut-off of traction power). The price payable under this items shall be extra over the erection rates of the items referred to above provided such work is not called for on account of non compliance with specifications, approved drawings and instructions given by the Railway from time to time. Where the prices under this item are applicable, the contractor shall finalize the quantities of various items of works to be done under a power block, jointly with the Railway Engineer prior to taking the work on hand. The erection or dismantling rate under this item will not be payable, if power block is given for a total duration of 4 hours or more in a day whether continuously or in different spells.

  Show more

Moreover, Payable weight shall be as per Inspection report.

Structure bond of different sizes will be fabricated by the contractor as per instruction of the site supervisor/Depot in charge.

The fabrication of bonds is to be done as per Railway Drg.

Price includes the cost for its erection.

Price includes the cost of nuts ,bolts ,ancillaries required for its erection.

All such dismantled materials shall be handed over to thepurchaser's stores depot.

The price shall cover erection of all components, required for thesuspension assembly including the appropriate suspension clamp and including small parts steelwork with bolts nuts etc, if any.

The price shall cover erection of all components, including the 9ton insulator assembly

All suchdismantled equipment/materials shall be handed over to the Railway stores depot.